Statute · United States Code
28 U.S.C. § 1499 — Liquidated damages withheld from contractors under chapter 37 of title 40
28 U.S.C. § 1499
- Type
- Statute
- Source
- United States Code
- Jurisdiction
- Federal
- Date
- 2025-01-06
- Topic
- bankruptcy
The United States Court of Federal Claims shall have jurisdiction to render judgment upon any claim for liquidated damages withheld from a contractor or subcontractor under section 3703 of title 40.
Citator
28 U.S.C. § 1499 — Liquidated damages withheld from contractors under chapter 37 of title 40 is in force in the current edition of the Code, and nothing recorded condemns it.
The United States Court of Federal Claims shall have jurisdiction to render judgment upon any claim for liquidated damages withheld from a contractor or subcontractor under section 3703 of title 40.