Opinion · Supreme Court of the United States
Ripley v. United States
32 S. Ct. 352
- Type
- Opinion
- Court
- Supreme Court of the United States
- Jurisdiction
- Federal
- Date
- 1912-03-11
- Topic
- general
recognizing “a corresponding duty that the agent’s judgment should be exercised — not capriciously or fraudulently, but reasonably and with due regard to the rights of both contracting parties”
Citator
- Cited by
- 62 opinions
RIPLEYv. UNITED STATES,223 U.S. 695(1912)
32 S.Ct. 352
RIPLEYv. UNITED STATES.
UNITED STATESv. RIPLEY.
APPEALS FROM THE COURT OF CLAIMS.
Nos. 498, 499.
Submitted December 22, 1911.
Decided March 11, 1912.
APPEAL and cross appeal from a judgment by the Court of Claims
for $14,732.05 in favor of Henry C. Ripley against the United
States, in a suit for the recovery of damages of a public work
consequent upon the action of the agent in charge.
By the act of June 13, 1902,32 Stat. 340, Congress
appropriated $250,000 for the completion of the work of improving
the harbor of Aransas Pass, Texas. The contract was awarded to
Henry C. Ripley. It provided for
Page 696
the completion of a jetty, having a brush foundation, to be
covered with a layer of stone, on which was to be built a
superstructure, with sloping sides and a top width of ten feet.
This superstructure was to be formed of a core or mound of
riprap, "and when in the judgment of the United States agent in
charge, this mound has become sufficiently consolidated, its gaps
shall be filled and its crest levelled; . . . large blocks shall
then be bedded in the crest of the mound."
It was provided that —
"Where the contract contemplates the placing of the materials
in the work, the material shall be placed securely and carefully
where directed by the U.S. Agent in charge. . . .
"All material furnished and work done under this contract
shall, before being accepted, be subject to a rigid inspection by
an inspector appointed on the part of the Government, and such as
does not conform to the specifications set forth in this contract
shall be rejected. The decision of the Engineer Officer in charge
as to quality and quantity shall be final."
The contract also provided that the work should be executed
under the supervision of the engineer officer in charge or his
duly authorized agent. The United States was to employ one or
more inspectors, and the contractor, without additional
compensation, was bound to furnish facilities for the inspection
of work and material. The contractor was to furnish extra labor
at cost prices, as determined by the engineer, and should furnish
board and lodging to Government employes at reasonable rates
satisfactory to the engineer. If the work was not diligently
prosecuted the contract might be annulled, or the engineer in
charge, "with the prior sanction of the Chief of Engineers, may
waive for a reasonable period the limit originally set for the
completion of the work and remit the charges for the expenses of
superintendence and inspection
Page 697
for so much time as in the judgment of the engineer officer in
charge may actually have been lost on account of . . . violence
of the elements, or by epidemic, or local or State quarantine
restrictions, or other unforeseeable causes of delay arising from
no fault of the contractor, and which actually prevented him from
commencing or completing the work within the period required by
the contract."
Claimant entered upon the performance of the contract August
18, 1903, and completed 2,100 feet of jetty when operations
ceased about September 17, 1904, owing to the exhaustion of the
appropriation.
About the time work began, without fault on the part of the
contractor or of the United States, there was a delay of about
thirty days, due to the fact that contractor's tug, while in
charge of a licensed pilot, was grounded on a sand bar. The
Government apparently incurred expenses for inspection during
this period and deducted that amount from Ripley's account.
Owing to an epidemic of yellow fever the force of the
contractor was disorganized, and work was necessarily suspended
for thirty days. The Government did not charge him with
inspection expenses during the fifteen days the quarantine was in
force, in a city through which the cars hauling the material were
prevented from passing. And the court held also that Ripley was
not chargeable with the inspection expenses for the other fifteen
days, during which his force was scattered as a result of the
epidemic.
During the progress of the work, a large number of blocks were
rejected by the inspector as not conforming to specifications.
"Many of those so rejected were afterwards accepted, but ninety
of the stones offered as crest blocks were rejected as such, and
were accepted and used as riprap and paid for as such. The
difference in the amount paid claimant for said stones used as
riprap and
Page 698
the amount he would have received if they had been used as crest
blocks" was allowed him by the Court of Claims. It found that "he
was compelled to furnish other crest blocks to take the place of
those rejected, which caused a delay of ten days to claimant in
the completion of the work."
It appears that the rejection of these blocks was due to a
difference in the method of measurement, the inspector insisting
that the blocks should be measured at the narrowest, thinnest and
shortest points. The contractor contended that mean or average
measurements should be taken, claiming that this was the
understanding of himself and the officer who drew the
specifications. The engineer at Galveston thereupon suggested
that the matter should be referred to the Chief of Engineers in
Washington; and later a supplementary agreement was drawn, which
permitted the use of blocks "which would make the work as stable,
or more stable, than if the dimensions conformed strictly to the
letter of the specifications. In consideration of which change
the contractor agrees to accept $5.00 per ton for all blocks
received under the supplementary agreement which would have been
rejected under the original specification."
The plaintiff's claim for additional compensation for extra
labor furnished the Government and for board and lodging
furnished its employes was rejected by the court, as also his
claim for damages for double handling caused by the inspector's
refusal to permit him to unload certain material on the jetty.
The contractor's principal claim, however, was for damage
caused by the delay resulting from the refusal of the inspector
in charge to permit crest blocks to be laid after the core had
fully consolidated. As long as the jetty was uncovered by these
blocks it was subject to the rough action of the waves, and the
plaintiff's employes were deprived of the advantage of working in
still water on the
Page 699
lee side of the jetty. The work began August 18, 1903, and the
court found as a fact "that in December, when plaintiff had
completed 200 feet of the core, he requested permission to lay
the blocks. This was refused, on the ground that the core had not
been consolidated. By the end of December he had completed 500
feet, and again requested permission to lay the blocks. The
inspector refused and continued to refuse permission to lay the
blocks until May 1, 1904, at which time 1,500 feet of the core
had been repaired and completed."
"Commencing in October, 1903, the contractor began to lay the
slope stones, and from December, 1903, until May, 1904, it was
manifest that large parts of the work done by him were fully
settled and consolidated. If the claimant had been permitted to
lay the crest blocks from the time on, as the work progressed,
there would have resulted an additional protection, which would
have enabled him to work sixty days more within the period
between that time and May 7, 1904, when the first crest block was
laid."
"The total cost to claimant of performing the contract,
exclusive of the cost of the granite and the cost of transport
and fitting up and repairs to barges, was $63,780. The total
number of days from the beginning to the completion of said work
was 392, making an average daily cost to the contractor of
$162.70. The work was completed on September 17, 1904. The number
of days of actual work performed was 131, of which 58 was
subsequent to the 30th day of April, 1904." "Claimant, under the
requirements of the specification, personally superintended the
work for the whole time. The value of his personal services while
so doing was $750 per month, but it does not appear that at this
particular time he had any other enterprise under way or any
other employment."
The court entered judgment for plaintiff for $14,832.05 — made
up of damage for difference between price of
Page 700
large blocks and riprap, delay caused by such rejection, value of
ten days' services of plaintiff during the delay, remission of
expenses for additional fifteen days during yellow fever
epidemic, remission of expenses while tug was grounded on a sand
bar, value of contractor's time during 60 days' delay occasioned
by refusal to permit crest blocks to be laid, $1,500, and average
daily expense $162.70, and remission of inspection charges during
the 60 days' delay.
After the case was argued here it was twice remanded (220 U.S. 491;
222 U.S. 144), and the Court of Claims made the following
additional findings of fact:
"When denying permission to the claimant to lay the crest
blocks, as stated in finding 7, the assistant engineer, who was
an experienced officer of the Government in such work, and who
was acting as inspector in immediate charge of the work, knew
that large parts of the core theretofore completed by the
claimant had fully settled and consolidated and were ready for
the crest blocks to be laid thereon.
"2. The refusal of said assistant engineer, as inspector in
immediate charge of the work, to allow crest blocks to be laid
when he knew that parts of the core had settled and consolidated
as aforesaid, was gross error and an act of bad faith on his
part.
"3. There was no protest made to the engineer in charge, whose
office was in Galveston, or to the Chief of Engineers, whose
office was in Washington, respecting the refusal of said
assistant engineer to permit the laying of crest blocks as
aforesaid. The claimant made frequent complaints to said
assistant engineer about the delays so caused by his refusal to
permit the laying of crest blocks.
"Claimant visited the office of the engineer in charge at
Galveston about once a month, and while there complained
generally that said assistant engineer, as inspector in immediate
charge of the work, was too strict with him in construing the
specifications and contract. No appeal,
Page 701
either written or otherwise, was taken or asked by the claimant
to either the engineer in charge or to the Chief of Engineers,
because of the said refusal to permit the laying of crest
blocks."
But the very extent of the power and the conclusive character of his decision raised a corresponding duty thatPage 702the agent's judgment should be exercised — not capriciously or fraudulently, but reasonably and with due regard to the rights of both the contracting parties. The finding by the court that the inspector's refusal was a gross mistake and an act of bad faith necessarily, therefore, leads to the conclusion that the contractor was entitled to recover the damages caused thereby.
The defendant claims that the plaintiff lost his right to recover because he failed to appeal to the Engineer in Charge, at Galveston, or to the Chief of Engineers, in Washington. But there was no requirement or provision for appeal in the contract. The clause relied on by the Government relates to the duty of inspection and acceptance, making the decision of the Engineer in Charge conclusive as to the quality and quantity of work and material. That part of the agreement had no reference to the settlement of the core. Whether it had sufficiently consolidated involved the determination of a matter of fact, varying from day to day. The contractor had to act or refrain from acting when the decision was made. That matter was expressly left to "the judgment of the United States agent in charge." The contractor in submitting to his decision did not lose his right to recover damages occasioned by the refusal to permit the crest blocks to be laid, when, as found by the court, this refusal was gross error and an act of bad faith.
The court, therefore, declared in plaintiff's favor on this issue. He appeals, however, on the ground that the court only allowed him $11,908.90, being for expenses and loss of time for sixty days, insisting that he was entitled to recover $28,953 as damages directly caused by this delay.
This claim is based on the fact that there were 392 days between the beginning and the completion of the work. But on account of Sundays, holidays and storms, there were only 131 working days. Of these, 58 were after April 30, 1904 — when, for the first time, the inspector permittedPage 703the crest blocks to be laid. The contractor contends that as it only took him 58 days after May 1, when the permission was given, to complete the work, and, as the court finds, that he was delayed for 60 days before the permission was given, it is evident that he could have finished the work before May 1, and is therefore entitled to recover the value of his own time and all the expenses for inspection and labor which were incurred after that date.
The findings of fact do not require any such conclusion. Prior to May 1 the contractor worked 73 days out of 247. But it does not appear how many of these workings days there were between August 18, 1903, when he began construction, and December, 1903, when he first applied for permission to lay the crest blocks. Neither is it shown how many workings day there were between the date of the first refusal and the first permission to lay the blocks; nor on how many of such working days the contractor was able to do labor of another character on the jetty. In the absence of such data it is impossible to verify plaintiff's calculations. The burden was on the contractor. If the evidence would have sustained his present claim he was bound to have applied, in due season, for additional findings of fact by the court. Our decision must be predicated on what appears in the present record. Inasmuch as the court found that $162.70 was the average daily expense, and assessed plaintiff's damage at 60 times that amount, it is evident that it considered that the contractor had been delayed for 60 average days, and not for 60 working days. He is, therefore, entitled to judgment for $9,762 expenses, $646.92 inspection charges, and $1,500 found to have been the value of his own time for that period of sixty days.
The other findings in his favor for items aggregating $2,822 must be reversed, and the cross appeal of the Government sustained.
The greater part of this sum was for loss and delay arising from the inspector's rejection of 90 large blocksPage 704as not complying with the specifications. The fact that the court gave judgment in Ripley's favor indicates that it was of opinion that the agent had made an improper decision. But so far as appears his only error was in construing the contract strictly, according to its terms, instead of adopting a method of mean or average measurement for which the contractor contended. The supplemental agreement was not retroactive so as to give the plaintiff a cause of action for the prior rejection, even though thereafter a different method of measurement was permitted.
The balance of the amount allowed the plaintiff was by way of returning the expenses of inspection which had been charged against him, during the suspension of the work while the tug was grounded on the bar and the contractor's force disorganized on account of the yellow fever epidemic. The contract provided that the expenses of inspection might in some cases be remitted but this could only be with the prior consent of the Chief of Engineers. There is no finding that such consent was given.
But the error in entering judgment in Ripley's favor as to any of these items, and the propriety of disallowing the others for which he sued arises from the fact that the officer's decision was binding. All these claims relate to matters which under the contract were submitted to the engineer. There is no finding that he acted in bad faith. Indeed, it is not even found that the decisions were erroneous, though that is implied. But the contract did not contemplate that the opinion of the court should be substituted for that of the engineer. In the absence of fraud, or gross mistake implying fraud, his decision on all these matters was conclusive.
On the findings of fact the plaintiff is entitled to recover $11,908.90, with interest as provided in Rev. Stat., § 1090. The judgment of the Court of Claims must be so modified andAffirmed.1Page 721
- Page 704 See order on p. 750,post. ↩